---



FORM 10-K



United States Securities and Exchange Commission

Washington, DC 20549



(Mark One)





For the fiscal year ended December 31, 2016.





For the transition period from-to-.



Commission File No. 1-6314



Tutor Perini Corporation

(Exact name of registrant as specified in its charter)













Securities registered pursuant to Section 12(b) of the Act:





Securities registered pursuant to Section 12(g) of the Act: None



Indicate by check mark if the registrant is a well-known seasoned issuer, as defined in Rule 405 of the Securities Act. Yes  ☑  No  ☐



Indicate by check mark if the registrant is not required to file reports pursuant to Section 13 or Section 15(d) of the Act. Yes ☐  No  ☑



Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes  ☑  No  ☐



Indicate by check mark whether the registrant has submitted electronically and posted on its corporate website, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files). Yes  ☑  No  ☐



Indicate by check mark if disclosure of delinquent filers pursuant to Item 405 of Regulation S-K (§ 229.405 of this chapter) is not contained herein, and will not be contained, to the best of registrant’s knowledge, in definitive proxy or information statements incorporated by reference in Part III of this Form 10-K or any amendment to this Form 10-K. ☑



Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer or a smaller reporting company. See definition of “accelerated filer,” “large accelerated filer” and “smaller reporting company” in Rule 12b-2 of the Exchange Act. (Check one):





Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes  ☐  No ☑



The aggregate market value of voting Common Stock held by non-affiliates of the registrant was $900,681,219 as of June 30, 2016, the last business day of the registrant’s most recently completed second fiscal quarter.



The number of shares of Common Stock, $1.00 par value per share, outstanding at February 17, 2017 was 49,222,934.



Documents Incorporated by Reference



Portions of the definitive proxy statement relating to the registrant’s annual meeting of stockholders are incorporated by reference into Part III of this Annual Report on Form 10-K.

 

---

 











TUTOR PERINI CORPORATION



2016 ANNUAL REPORT ON FORM 10-K



TABLE OF CONTENTS







 

---

 

PART I.



Forward-Looking Statements



The statements contained in this Annual Report on Form 10-K that are not purely historical are forward-looking statements within the meaning of Section 27A of the Securities Act of 1933 and Section 21E of the Securities Exchange Act of 1934 (the “Exchange Act”), including without limitation, statements regarding our management’s expectations, hopes, beliefs, intentions or strategies regarding the future and statements regarding future guidance or estimates and non-historical performance. These forward-looking statements are based on our current expectations and beliefs concerning future developments and their potential effects on us. Our expectations, beliefs and projections are expressed in good faith, and we believe there is a reasonable basis for them. There can be no assurance that future developments affecting us will be those that we have anticipated. These forward-looking statements involve a number of risks, uncertainties (some of which are beyond our control) or other assumptions that may cause actual results or performance to be materially different from those expressed or implied by such forward-looking statements. These risks and uncertainties are listed and discussed in Item 1A. Risk Factors, below. We undertake no obligation to update or revise any forward-looking statements, whether as a result of new information, future events or otherwise, except as may be required under applicable securities laws.



ITEM 1. BUSINESS



General



Tutor Perini Corporation, formerly known as Perini Corporation, was incorporated in 1918 as a successor to businesses which had been engaged in providing construction services since 1894. Tutor Perini Corporation (together with its consolidated subsidiaries “Tutor Perini,” the “Company,” “we,” “us,” and “our,” unless the context indicates otherwise) is a leading construction company, based on revenue, as ranked by Engineering News-Record (“ENR”), offering diversified general contracting, construction management and design-build services to private customers and public agencies throughout the world. Our corporate headquarters are in Los Angeles (Sylmar), California, and we have various other principal office locations throughout the United States and certain U.S. territories (see Item 2. Properties for a listing of our major facilities). Our common stock is listed on the New York Stock Exchange under the symbol “TPC.” We are incorporated under the laws of the Commonwealth of Massachusetts.



We and our predecessors have provided construction services since 1894 and have established a strong reputation within our markets by executing large, complex projects on time and within budget while adhering to strict quality control measures. We offer general contracting, pre-construction planning and comprehensive project management services, including the planning and scheduling of the manpower, equipment, materials and subcontractors required for a project. We also offer self-performed construction services including site work; concrete forming and placement; steel erection; electrical; mechanical; plumbing; and heating, ventilation and air conditioning (HVAC). During 2016, we performed work on more than 1,500 construction projects.



Our business is conducted through three segments: Civil, Building and Specialty Contractors, as described below in the “Business Segment Overview.”



We are recognized as one of the leading civil contractors in the United States, as evidenced by our past and current performance on several of the country’s largest mass-transit and transportation projects, such as the McCarran International Airport Terminal 3 in Las Vegas, the East Side Access project in New York City, the San Francisco Central Subway extension to Chinatown and major portions of the Red Line Subway project in Los Angeles. We are also recognized as one of the leading building contractors in the United States, as evidenced by our performance on several of the largest hospitality and gaming projects, including CityCenter and the Cosmopolitan Casino and Resort in Las Vegas.



In 2008, we embarked upon a strategy to better align our business to pursue markets with higher profit margins and the best long-term growth potential, while maintaining our presence as a leading contractor in the general building market. In September 2008, our predecessors, Perini Corporation and Tutor-Saliba Corporation (“Tutor-Saliba”), completed a merger which provided us with enhanced opportunities for growth not available to us on a stand-alone basis through increased size, scale, bonding capacity, immediate access to multiple geographic regions, management capabilities, complementary assets and expertise in large civil projects. 



In 2010 and 2011, we took advantage of opportunities to expand our Company vertically and geographically through the strategic acquisitions of seven companies with demonstrated success in their respective markets. These acquisitions strengthened our geographic presence in our Building and Civil segments and also significantly increased our specialty contracting capabilities. In 2011, we completed an internal reorganization of our reporting segments with the creation of the Specialty Contractors segment, which we describe below.



We believe our acquisitions have enabled us to realize cross-selling opportunities across an expanded geographic footprint, while continuing to focus on vertical integration through increased self-perform work capabilities, thus further improving profitability and providing greater stability during economic cycles.

---

 



Business Segment Overview



Civil Segment



Our Civil segment specializes in public works construction and the replacement and reconstruction of infrastructure across most of the major geographic regions of the United States. Our civil contracting services include construction and rehabilitation of highways, bridges, tunnels, mass-transit systems, and water management and wastewater treatment facilities.



The Civil segment is comprised of the Company’s legacy heavy civil construction operations (civil operations of our predecessors, Perini Corporation, Tutor-Saliba and its subsidiary, Black Construction) and the following three companies acquired by the Company in 2011: Frontier-Kemper, Lunda Construction, and Becho. Frontier-Kemper is a heavy civil contractor engaged in the construction of tunnels for highways, railroads, subways and rapid transit systems; the construction of shafts and other facilities for water supply, wastewater transport and hydroelectric projects; and the development and equipping of mines with innovative hoisting, elevator and vertical conveyance systems. Lunda Construction is a heavy civil contractor engaged in the construction, rehabilitation and maintenance of bridges, railroads and other civil structures throughout the United States. Becho is engaged in drilling, foundation and excavation support for shoring, bridges, piers, roads and highway projects, primarily in the southwestern United States. We believe that the Company has benefitted through these acquisitions by an expanded geographic presence, enhanced civil construction capabilities and the addition of experienced management with proven, successful track records.



Our Civil segment’s customers primarily award contracts through one of two methods: the traditional public “competitive bid” method, in which price is the major determining factor, or through a request for proposals where contracts are awarded based on a combination of technical capability and price.



Traditionally, our Civil segment’s customers require each contractor to pre-qualify for construction business by meeting criteria that include technical capabilities and financial strength. Our financial strength and outstanding record of performance on challenging civil works projects often enable us to pre-qualify for projects in situations where smaller, less diversified contractors are unable to meet the qualification requirements. We believe this is a competitive advantage that makes us an attractive partner on the largest, most complex infrastructure projects and prestigious design-build, or DBOM (design-build-operate-maintain) contracts, which combine the nation’s top contractors with engineering firms, equipment manufacturers and project development consultants in a competitive bid selection process to execute highly sophisticated projects.



In its 2016 rankings, ENR ranked us as the nation’s fourth largest domestic heavy contractor, fourth largest contractor in the transportation market and tenth largest contractor overall.



We believe the Civil segment provides significant opportunities for growth due to the age and condition of existing infrastructure coupled with large government funding sources aimed at the replacement and reconstruction of aging U.S. infrastructure and popular, often bipartisan, support from the public and elected officials for infrastructure improvement programs. Funding for major civil infrastructure projects is typically provided through a combination of one or more of the following: local, regional, state and federal loans; grants; other direct allocations sourced through tax revenue; bonds; and user fees.



We have been active in civil construction since 1894 and believe we have a particular expertise in large, complex civil construction projects. We have completed or are currently working on some of the most significant civil construction projects in the United States. For example, we are currently working on various segments of the East Side Access project in New York City; the first phase of the California High-Speed Rail project; the Alaskan Way Viaduct Replacement (SR-99 bored tunnel) project in Seattle, Washington; the Third Street Light Rail-Central Subway project in San Francisco, California; the platform over the eastern rail yard and the Amtrak Tunnel at Hudson Yards in New York City; and the rehabilitation of the Verrazano-Narrows Bridge in New York. We have also performed runway widening and reconstruction projects at the John F. Kennedy International Airport in Queens, New York, and completed the New Irvington Tunnel in Fremont, California,  the Caldecott Tunnel Fourth Bore project near Oakland, California, and express toll lanes along I-95 in Maryland. In January of 2017, a joint-venture team we are leading was awarded a $1.4 billion contract for the Purple Line Segment 2 expansion project in Los Angeles, California.



Building Segment



Our Building segment has significant experience providing services to a number of specialized building markets for private and public works customers, including the hospitality and gaming, transportation, health care, corporate and municipal offices, sports and entertainment, education, correctional facilities, biotech, pharmaceutical, industrial and high-tech markets. We believe the success of the Building segment results from our proven ability to manage and perform large, complex projects with aggressive fast-track schedules; elaborate designs; and advanced mechanical, electrical and life safety systems, while providing accurate budgeting and strict quality control. Although price is a key competitive factor, we believe our strong reputation, long-standing customer relationships and significant level of repeat and referral business have enabled us to achieve our leading position.

---

 



The Building segment is comprised of several operating units that provide general contracting, design-build, preconstruction and construction services in various regions of the United States. Tutor Perini Building Corp. focuses on large, complex building projects nationwide, including significant projects in the hospitality and gaming, commercial office, education, government facilities, and multi-unit residential markets. Rudolph and Sletten focuses on large, complex projects in California in the commercial office, technology, industrial, education, and government facilities markets. Roy Anderson Corp. provides its services, including disaster rapid response services, to public and private customers primarily throughout the southeastern United States. Perini Management Services provides diversified construction and design-build services to U.S. military and government agencies, as well as to surety companies and multi-national corporations in the United States and locations overseas. We believe that our national resources and strong résumé of notable projects will enable future growth on large, complex building projects.



In its 2016 rankings, ENR ranked us as the sixth largest domestic building contractor. We are a recognized leader in the hospitality and gaming market, specializing in the construction of high-end resorts and casinos. We work with hotel operators, Native American tribal councils, developers and architectural firms to provide diversified construction services to meet the challenges of new construction and renovation of hotel and resort properties. We believe that our reputation for completing projects on time is a significant competitive advantage in this market, as any delay in project completion could result in significant loss of revenue for the customer.



We have recently completed, or are currently working on, large private and public building projects across a wide array of building end markets, including commercial offices, multi-unit residential, health care, hospitality and gaming, transportation, education, and entertainment. Specific projects include a large technology research and development office building in northern California for a confidential technology customer; the Panorama Tower in Miami, Florida; Tower C and Tower D at Hudson Yards in New York City; the Washington Hospital expansion in Fremont, California; the Graton Rancheria Resort and Casino in Rohnert Park, California; the Chumash Casino Resort expansion in Santa Ynez, California; the Scarlet Pearl Casino Resort in D’Iberville, Mississippi; the Broadway Plaza retail development in Walnut Creek, California; Kaiser Hospital Buildings in San Leandro and Redwood City, California; and courthouses in San Bernardino and San Diego, California and Broward County, Florida. As a result of our reputation and track record, we were previously awarded and completed contracts for several marquee projects in the hospitality and gaming market, including the Resorts World New York Casino in Jamaica, New York, and CityCenter, the Cosmopolitan Resort and Casino, the Wynn Encore Hotel and Planet Hollywood, all in Las Vegas, Nevada. These projects span a wide array of building end markets and illustrate our Building segment’s résumé of successfully completed large-scale public and private projects.



Specialty Contractors Segment



Our Specialty Contractors segment specializes in electrical, mechanical, plumbing, HVAC, fire protection systems and pneumatically placed concrete for a full range of civil and building construction projects in the industrial, commercial, hospitality and gaming, and mass-transit end markets. This segment provides the Company with unique strengths and capabilities that position us as a full-service contractor with greater control over scheduled work, project delivery and risk management.



The Specialty Contractors segment is comprised of several operating units that provide unique services in various regions of the United States. Five Star Electric is the largest electrical contractor in New York City, providing construction services in the electrical sector, including power, lighting, fire alarm, security, telecommunications, low voltage and wireless systems. Five Star Electric has established itself as an industry leader performing work in both the public and private sectors, including high-end residential, hotel and commercial towers, transportation, water treatment plants, schools and universities, health care, retail, sports and government facilities. Fisk Electric covers many of the major commercial, transportation and industrial electrical construction markets in the southwestern and southeastern United States, with the ability to cover other attractive markets nationwide. Fisk’s expertise is in technology design and the development of electrical and technology systems for major projects spanning a broad variety of project types, including commercial office buildings, sports arenas, hospitals, research laboratories, hotels and casinos, convention centers, manufacturing plants, refineries and water and wastewater treatment facilities. WDF, Nagelbush and Desert Mechanical each provide mechanical, plumbing, HVAC and fire protection services to a range of customers in a wide variety of markets, including transportation, commercial/industrial, schools and universities and residential. WDF is one of the largest mechanical contractors servicing the New York City metropolitan region, Nagelbush operates primarily in Florida, and Desert Mechanical operates primarily in the western United States. Superior Gunite specializes in pneumatically placed structural concrete utilized in infrastructure projects nationwide, such as bridges, dams, tunnels and retaining walls.



In its 2016 rankings, ENR ranked us as the fifth largest electrical contractor1, eleventh largest mechanical contractor and tenth largest specialty contractor1 in the United States. Through Five Star Electric and WDF, collectively, we are also the largest specialty contractor in the New York City metropolitan area.









1 This ranking represents the collective revenue of the Company’s specialty contracting subsidiaries as reported to ENR.

---

 



We have recently completed, or are currently working on, various electrical and mechanical projects at the World Trade Center and at Hudson Yards in New York City, two signal system modernization projects in New York City and electrical work for the new hospital at the University of Texas Southwestern Medical Center in Dallas, Texas. This segment has supported, or is currently supporting, several large projects in our Building and Civil segments, including the Alaskan Way Viaduct Replacement (SR-99 bored tunnel) project in Seattle, Washington; the McCarran International Airport Terminal 3 in Las Vegas, Nevada; the Resorts World New York Casino in Jamaica, New York; various segments of the Greenwich Street Corridor and East Side Access projects in New York City; the Caldecott Tunnel Fourth Bore project near Oakland, California; the New Irvington Tunnel in Fremont, California; and several marquee projects in the hospitality and gaming market, including CityCenter, the Cosmopolitan Resort and Casino and Planet Hollywood, all in Las Vegas, Nevada.



The majority of work performed by our Specialty Contractors units is contracted directly with state and local municipal agencies, real estate developers, general contractors, commercial and industrial customers and school districts; additionally, a smaller, but growing, component of its work is performed as a subcontractor to the our Building and Civil segments.



Markets and Customers



We provide diversified construction services to a variety of end markets and customers. The following tables set forth certain reportable segment information relating to the Company’s operations for the years ended December 31, 2016, 2015 and 2014.

























---

 











State and Local Agencies. Our state and local government customers include state transportation departments, metropolitan authorities, cities, municipal agencies, school districts and public universities. We provide services to our state and local customers primarily pursuant to contracts awarded through competitive bidding processes. Our building construction services for state and local government customers have included judicial and correctional facilities, schools and dormitories, health care facilities, convention centers, parking structures and other municipal buildings. The vast majority of our civil contracting and building construction services are provided in locations throughout the United States and its territories.



Private Owners. Our private customers include real estate developers, health care companies, technology companies, hospitality and gaming resort owners, Native American sovereign nations, public corporations and private universities. We provide services to our private customers through negotiated contract arrangements, as well as through competitive bids.



Federal Agencies. Our federal government customers include the U.S. State Department, the U.S. Navy, the U.S. Army Corps of Engineers, the U.S. Air Force and the National Park Service. We provide services to federal agencies primarily pursuant to contracts for specific or multi-year assignments that involve new construction or infrastructure repairs or improvements. A portion of our revenue from federal agencies is derived from projects in overseas locations, which we expect to continue for the foreseeable future as a result of our experience and strong relationships with federal agencies, together with anticipated expenditures for defense, diplomatic and security-related construction work.



Most federal, state and local government contracts contain provisions that permit the termination of contracts, in whole or in part, for the convenience of the government, among other reasons.



For additional information on revenue and total assets by geographic location, see Note 10 of the Notes to Consolidated Financial Statements.



---

 

Backlog



Backlog in our industry is a measure of the total value of work that is remaining to be performed on contracts awarded. We include a construction project in our backlog when a contract is awarded or a letter of commitment is obtained and we believe adequate funding is in place. As a result, we believe our backlog is firm, and although cancellations or scope adjustments may occur, historically they have not been material. Our backlog by segment, end market and customer type is presented in the following tables:











We estimate that approximately $3.4 billion, or 54%, of our backlog as of December 31, 2016 will be recognized as revenue in 2017.





























---

 



Types of Contracts



The contracting and management services we provide consist of planning and scheduling the manpower, equipment, materials and subcontractors required for the timely completion of a project in accordance with the terms, plans and specifications contained in a construction contract. We provide these services by entering into traditional contracting arrangements as follows:



Fixed price contracts account for a substantial portion of our revenue and are expected to continue to represent a sizeable percentage of both total revenue and backlog. The composition of revenue and backlog by type of contract for 2016, 2015 and 2014 is as follows:



















---

 

Competition



The markets in which we compete include numerous competitors. In the small to mid-sized work that we have targeted, we have continued to experience strong pricing competition from our competitors. Much of the work that we target, however, is for larger, more complex projects where there are fewer active market participants because of the enhanced capabilities and resources required to perform the work. As a result, on these larger projects we typically face fewer competitors. Despite this, over the past two years we have seen increased competition especially from foreign competitors that have been pursuing major projects in the United States due to the relatively larger size and significant number of U.S. opportunities. We anticipate that the increased level of foreign competition will persist for the foreseeable future.



In our Civil segment, we compete principally with large civil construction firms, including (alphabetically) Dragados USA; Fluor Corporation; Granite Construction; Kiewit Corporation; Skanska USA; Traylor Bros., Inc.; and The Walsh Group. In our Building segment, we compete with a variety of national and regional contractors. Our primary competitors are (alphabetically) AECOM (through its acquisitions of Tishman Construction and Hunt Construction Group); Balfour Beatty Construction; Clark Construction Group; DPR Construction; Gilbane, Inc.; Hensel Phelps Construction Co.; McCarthy Building Companies, Inc.; Skanska USA; Suffolk Construction; and Turner Construction Company. In our Specialty Contractors segment, we compete principally with various regional and local electrical, mechanical and plumbing subcontractors. We believe price, experience, reputation, responsiveness, customer relationships, project completion track record, schedule control, risk management and quality of work are key factors customers consider when awarding contracts.



Construction Costs



If prices for materials, labor or equipment increase excessively, provisions in certain types of contracts often shift all or a major portion of any adverse impact to the customer. In our fixed price contracts, we attempt to insulate ourselves from the unfavorable effects of inflation, when possible, by incorporating escalating wage and price assumptions into our construction cost estimates, by obtaining firm fixed price quotes from major subcontractors and material suppliers, and by purchasing required materials early in the project schedule. Construction and other materials used in our construction activities are generally available locally from multiple sources and have been in adequate supply during recent years. Labor resources for our domestic projects are largely obtained through various labor unions with which we are associated. We have not experienced significant labor shortages in recent years, nor do we expect to in the future. We employ expatriate and local labor in selected overseas areas.



Environmental Matters



Our properties and operations are subject to federal, state and municipal laws and regulations relating to the protection of the environment, including requirements for water discharges; air emissions; the use, management and disposal of solid or hazardous materials or wastes; and the cleanup of contamination. In certain circumstances, we may also be required to hire subcontractors to dispose of hazardous materials encountered on a project in accordance with a plan approved in advance by the owner. We believe that we are in substantial compliance with all applicable environmental laws and regulations, and we continually evaluate whether we must take additional steps to ensure compliance with those laws and regulations. However, future requirements or amendments to current laws or regulations imposing more stringent requirements could require us to incur additional costs to maintain or achieve compliance.



In addition, some environmental laws, such as the U.S. federal “Superfund” law and similar state statutes, can impose liability for the entire cost of cleanup of contaminated sites upon any of the current or former owners or operators or upon parties who generated waste at, or sent waste to, these sites, regardless of who owned the site at the time of the release or the lawfulness of the original disposal activity. Contaminants have been detected at some of the sites that we own and where we have worked as a contractor in the past, and we have incurred costs for the investigation and remediation of hazardous substances. We believe that our liabilities for these sites are not material, either individually or in the aggregate. We have pollution liability insurance coverage for such matters, and we receive indemnification from customers to cover the risks associated with environmental remediation.



Insurance and Bonding



All of our properties and equipment, as well as those of our joint ventures, are covered by insurance in amounts that we believe are consistent with our risk of loss and industry practice. Our wholly owned subsidiary, PCR Insurance Company, issues deductible reimbursement policies for subcontractor default insurance, auto liability, general liability and workers’ compensation insurance, allowing us to centralize our claims and risk management functions to reduce our insurance-related costs.



As a normal part of the construction business, we are often required to provide various types of surety bonds as an additional level of security of our performance. We also require many of our higher-risk subcontractors to provide surety bonds as security for payment of subcontractors and suppliers and to guarantee their performance. As an alternative to traditional surety bonds, we also have purchased subcontractor default insurance for certain construction projects to insure against the risk of subcontractor default.



---

 

Employees



The number of our employees varies based on the number of active projects, the type and magnitude of those projects, as well as our position within the lifecycle of those projects. Our total number of employees as of December 31, 2016 was 11,603.  



We are signatory to numerous local and regional collective bargaining agreements, both directly and through trade associations, as a union contractor. These agreements cover all necessary union crafts and are subject to various renewal dates. Estimated amounts for wage escalation related to the expiration of union contracts are included in our bids on various projects; accordingly, the expiration of any union contract in the next year is not expected to have any material impact on us. During the past several years, we have not experienced any significant work stoppages caused by our union employees.



Financial information about geographic areas is discussed in Note 10 to the Consolidated Financial Statements under the heading “Geographic Information.”



Available Information



Our website address is www.tutorperini.com. In the ‘‘Investor Relations’’ portion of our website, under “Financial Reports,” subsection “SEC Filings,” you may obtain free electronic copies of our annual reports on Form 10-K, quarterly reports on Form 10‑Q, current reports on Form 8-K and all amendments to those reports, as well as reports under Section 16 of the Exchange Act of transactions in our stock by our directors and executive officers. These reports are made available on our website as soon as reasonably practicable after we electronically file them with the Securities and Exchange Commission (“SEC”). These reports, and any amendments to them, are also available at the Internet website of the SEC, www.sec.gov. The public may also read and copy any materials we file with the SEC at the SEC’s Public Reference Room located at 100 F Street, N.E., Washington, D.C. 20549. In order to obtain information about the operation of the Public Reference Room, you may call 1-800-732-0330. We also maintain various documents, including our Code of Business Conduct and Ethics, Corporate Governance Guidelines and the charters of the Committees of our Board of Directors in the “Corporate Governance” portion of our website.

  

ITEM 1A. RISK FACTORS



We are subject to a number of known and unknown risks and uncertainties that could have a material adverse effect on our operations. Set forth below, and elsewhere in this report, are descriptions of the risks and uncertainties that could cause our actual results to differ materially from the results contemplated by the forward-looking statements contained in this report and could have a material adverse effect on our financial condition, results of operations and cash flows.



A significant slowdown or decline in economic conditions could adversely affect our operations.



Any significant decline in economic conditions in any of the markets we serve or uncertainty regarding the economic outlook, could result in a decline in demand for infrastructure projects and commercial building developments. In addition, any instability in the financial and credit markets could negatively impact our customers’ ability to pay us on a timely basis, or at all, for work on projects already under construction, could cause our customers to delay or cancel construction projects in our backlog or could create difficulties for customers to obtain adequate financing to fund new construction projects. Such consequences could have an adverse impact on our future operating results. Lastly, we are more susceptible to adverse economic conditions in New York and California, as a significant portion of our operations are concentrated in those states.



If we are unable to accurately estimate the overall risks, revenue or costs on a contract, we may achieve a lower than anticipated profit or incur a loss on that contract.



Accounting for contract related revenue and costs requires management to make significant estimates and assumptions that may change significantly throughout the project lifecycle, resulting in a material impact to our consolidated financial statements. In addition, cost overruns on fixed price and GMP contracts may result in lower profits or losses.



Our contracts require us to perform extra, or change order, work, which can result in disputes or claims and adversely affect our working capital, profits and cash flows.



Our contracts generally require us to perform extra, or change order, work as directed by the customer even if the customer has not agreed in advance on the scope or price of the work to be performed. This process may result in disputes or claims over whether the work performed is beyond the scope of work directed by the customer and/or exceeds the price the customer is willing to pay for the work performed. To the extent we do not recover our costs for this work or there are delays in the recovery of these costs, our cash flows and working capital could be adversely impacted.

---

 



We are subject to significant legal proceedings which, if determined adversely to us, could harm our reputation, preclude us from bidding on future projects and/or have a material effect on us. We also may invest significant working capital on projects while legal proceedings are being settled.



We are involved in various lawsuits, including the legal proceedings described under Note 7 of the Notes to Consolidated Financial Statements. Litigation is inherently uncertain, and it is not possible to accurately predict what the final outcome will be of any legal proceeding. We must make certain assumptions and rely on estimates, which are inherently subject to risks and uncertainties, regarding potential outcomes of legal proceedings in order to determine an appropriate contingent liability and charge to income. Any result that is materially different than our estimates could have a material adverse effect on our financial condition, results of operations and cash flows. In addition, any adverse judgments could harm our reputation and preclude us from bidding on future projects.



We occasionally bring claims against project owners for additional cost exceeding the contract price or for amounts not included in the original contract price. When these types of events occur and unresolved claims are pending, we may invest significant working capital in projects to cover cost overruns pending the resolution of the relevant claims. A failure to promptly recover on these types of claims could have a material effect on our liquidity and financial results.



Competition for new project awards is intense, and our failure to compete effectively could reduce our market share and profits.



New project awards are determined through either a competitive bid basis or on a negotiated basis. Projects are generally awarded based upon price but often take into account other factors, such as technical approach and qualifications, duration of project execution and past performance on similar projects completed. Within our industry, we compete with many international, regional and local construction firms. Some of these competitors have achieved greater market penetration than we have in the markets in which we compete, and some have greater resources than we do. If we are unable to compete successfully in such markets, our relative market share and profits could be reduced.



We may not fully realize the revenue value reported in our backlog due to cancellations or reductions in scope.



As of December 31, 2016, our backlog of uncompleted construction work was approximately $6.2 billion. The revenue projected in our backlog may not be realized or, if realized, may not result in profits. For example, the cancellation or reduction in scope of any project in our backlog could have a material adverse effect on our financial condition, results of operations and cash flows.



We have a substantial amount of indebtedness which could adversely affect our financial position and prevent us from fulfilling our obligations under our debt agreements.



We currently have, and expect to continue to have, a substantial amount of indebtedness. As of December 31, 2016, we had total debt of $759.5 million. If we are unable to meet the terms of the financial covenants or fail to comply with any of the other restrictions contained in the agreements governing our indebtedness, an event of default could occur, causing the debt related to such agreement to become immediately due. If such acceleration occurs, we may not be able to repay such indebtedness as required. Since indebtedness under our Credit Agreement is secured by substantially all of our assets, acceleration of this debt could result in foreclosure of those assets and a negative impact on our operations. In addition, a failure to meet the terms of our Credit Agreement could result in a reduction of future borrowing capacity under the Credit Agreement, causing a loss of liquidity. A loss of liquidity could adversely impact our ability to execute projects in our backlog, obtain new projects, engage subcontractors, and attract and retain key employees.



Our actual results could differ from the assumptions and estimates used to prepare our financial statements.



In preparing our financial statements, we are required under accounting principles generally accepted in the United States (“GAAP”) to make estimates and assumptions as of the date of the financial statements. These estimates and assumptions affect the reported values of assets, liabilities, revenue and expenses, and the disclosure of contingent assets and liabilities. Areas requiring significant estimates by our management include, but are not limited to:



• recognition of contract revenue, costs, profits or losses in applying the principles of percentage-of-completion accounting;

• recognition of revenue related to project incentives or awards we expect to receive;

• recognition of recoveries under contract change orders or claims;

• estimated amounts for expected project losses, warranty costs, contract close-out or other costs;

• collectability of billed and unbilled accounts receivable;

• asset valuations;

• income tax provisions and related valuation allowances;

---

 

• determination of expense and potential liabilities under pension and other post-retirement benefit programs; and

• accruals for other estimated liabilities, including litigation and insurance revenue/reserves.



Our actual business and financial results could differ from our estimates of such results, which could have a material negative impact on our financial condition and reported results of operations.



The level of federal, state and local government spending for infrastructure and other public projects could adversely affect the number of projects available to us in the future.



The civil construction and public-works building markets are dependent on the amount of work funded by various government agencies, which depends on many factors, including the condition of the existing infrastructure and buildings; the need for new or expanded infrastructure and buildings; and federal, state and local government spending levels. As a result, our future operating results could be negatively impacted by any decrease in demand for public projects or decrease or delay in government funding, which could result from a variety of factors, including delays in the sale of voter-approved bonds, budget shortfalls, credit rating downgrades or long-term impairment in the ability of state and local governments to raise capital in the municipal bond market.



The construction services industry is highly schedule driven, and our failure to meet the schedule requirements of our contracts could adversely affect our reputation and/or expose us to financial liability.



Many of our contracts are subject to specific completion schedule requirements. Any failure to meet contractual schedule requirements could subject us to liquidated damages, liability for our customer’s actual cost arising out of our delay and damage to our reputation.



We require substantial personnel, including construction and project managers and specialty subcontractor resources to execute and perform our contracts in backlog. The successful execution of our business strategies is also dependent upon our ability to attract, retain and implement succession plans for key officers.



Our ability to execute and perform on our contracts in backlog depends in large part upon our ability to hire and retain highly skilled personnel, including project and construction management and trade labor resources, such as carpenters, masons and other skilled workers. In the event we are unable to attract, hire and retain the requisite personnel and subcontractors necessary to execute and perform our backlog, we may experience delays in completing projects in accordance with project schedules or an increase in expected costs, both of which could have a material adverse effect on our financial results, our reputation and our relationships. In addition, if we lack the personnel and specialty subcontractors necessary to perform on our current contract backlog, we may find it necessary to curtail our pursuit of new projects.



The execution of our business strategies also substantially depends on our ability to retain several key members of our management. Losing any of these individuals could adversely affect our business. The majority of these key officers are not bound by employment agreements. Volatility or lack of positive performance in our stock price may adversely affect our ability to retain key staff to whom we have provided share-based compensation. Additionally, because a substantial portion of our key executives' compensation is placed "at risk" and linked to the performance of our business, when our operating results are negatively impacted, we are at greater risk of employee turnover. If we lose our existing key executives and are unable to execute a succession plan our operating results would likely be harmed.



Systems and information technology interruption and breaches in data security could adversely impact our ability to operate and negatively impact our operating results.



We are reliant on computer and other information technology that could be interrupted or damaged by a variety of factors including, but not limited to, cyber-attacks, natural disasters, power loss, telecommunications failures, acts of war, computer viruses and physical damage. The resulting consequences could include a loss of critical data, a delay in operations or an unintentional disclosure of confidential information, any of which could have a material impact to our Company and its consolidated financial statements.



Our participation in construction joint ventures exposes us to liability and/or harm to our reputation for failures by our partners.



As part of our business, we enter into joint venture arrangements typically to jointly bid on and execute particular projects, thereby reducing our risk profile while enhancing the execution capability and financial reward of project teams. Success on these joint projects depends in large part on whether our joint-venture partners satisfy their contractual obligations. We and our joint-venture partners are generally jointly and severally liable for all liabilities and obligations of our joint ventures. If a joint venture partner fails to perform or is financially unable to bear its portion of required capital contributions or other obligations, including liabilities stemming from lawsuits, we could be required to make additional investments, provide additional services or pay more than our proportionate share of a liability to make up for our partner’s shortfall. Further, if we are unable to adequately address our partner’s

---

 

performance issues, the customer may terminate the project, which could result in legal liability to us, harm our reputation, reduce our profit on a project or, in some cases, result in a loss.



We are subject to a number of risks as a U.S. government contractor, which could harm our reputation, result in fines or penalties against us and/or adversely impact our financial condition.



Failure to comply with laws and regulations related to government contracts could result in contract termination, suspension or debarment from contracting with the U.S. government, civil fines and criminal prosecution, any of which could have a material impact on our consolidated financial statements and future financial condition and performance.



Conversion of our outstanding Convertible Notes could dilute ownership interests of existing stockholders and could adversely affect the market price of our common stock.



Based on the terms of the indenture for the Convertible Notes, we may redeem the Convertible Notes in cash, shares of our common stock or a combination of the two. As a result, a conversion of some or all of the Convertible Notes may dilute the ownership interests of existing stockholders. Any sales in the public market of our common stock issuable upon such conversion of the Convertible Notes could cause the price of our common stock to decline. In addition, the existence of the Convertible Notes may encourage short selling by market participants because a conversion of the Convertible Notes could depress the price of our common stock.



We may need to include the potential dilutive impact of our Convertible Notes in our diluted earnings per share calculation.



We currently intend to pay the principal amount of our Convertible Notes in cash; therefore, we have not included the potential dilutive effect of our Convertible Notes in our diluted earnings per share calculations. If, however, there is a change in future circumstances as a result of a decline in our projected cash flow or for other reasons, we may conclude at such time that it will be preferable to use shares to satisfy the Convertible Notes. Such a change in our intentions would result in the inclusion of the potential dilutive impact of the Convertible Notes in our diluted earnings per share calculation, which would result in a decrease in our diluted earnings per share. 



Weather can significantly affect our revenue and profitability.



Inclement weather conditions, such as significant storms and unusual temperatures, can impact our ability to perform work. Adverse weather conditions can cause delays and increases in project costs, resulting in variability in our revenue and profitability.



Our international operations expose us to economic, political and other risks, as well as uncertainty related to U.S. Government funding, which could adversely affect our revenue and earnings. In addition, we could be adversely affected by violations of the U.S. Foreign Corrupt Practices Act and similar worldwide anti-bribery laws.



For the year ended December 31, 2016, we derived approximately $170.7 million of revenue from our work on projects located outside of the United States. Our international operations expose us to risks inherent in doing business in certain hostile regions outside the United States, including political risks; risks of loss due to acts of war; unstable economic, financial and market conditions; potential incompatibility with foreign subcontractors and vendors; foreign currency controls and fluctuations; trade restrictions; logistical challenges; variations in taxes; and changes in labor conditions, labor strikes and difficulties in staffing and managing international operations. Failure to successfully manage risks associated with our international operations could result in higher operating costs than anticipated or could delay or limit our ability to generate revenue and income from construction operations in key international markets.



The U.S. federal government has approved various spending bills for the construction of defense- and diplomacy-related projects and has allocated significant funds to the defense of U.S. interests around the world from the threat of terrorism. The federal government has also approved funds for development in conjunction with the relocation of military personnel into Guam. However, federal government funding levels for construction projects in the Middle East have decreased significantly over the past several years as the U.S. government has reduced the number of military troops and support personnel in the region. As a result, we have seen a decrease in the number and size of federal government projects available to us in this region. Any decrease in U.S. federal government funding for projects in Guam or in other U.S. Territories or countries in which we are pursuing work may result in project delays or cancellations, which could reduce our revenue and earnings.



Finally, the U.S. Foreign Corrupt Practices Act (“FCPA”), the U.K. Bribery Act of 2010, and similar anti-bribery laws in other jurisdictions generally prohibit companies and their intermediaries from making improper payments for the purpose of obtaining or retaining business. While our policies mandate compliance with these anti-bribery laws, there is no assurance that our internal control policies and procedures will protect us from circumstances or actions that could result in possible criminal penalties or other sanctions, including contract cancellations or debarment and loss of reputation, any of which could have a material adverse impact on our business, financial condition, and results of operations.

---

 



In connection with mergers and acquisitions, we have recorded goodwill and other intangible assets that could become impaired and adversely affect our operating results. Assessing whether impairment has occurred requires us to make significant judgments and assumptions about the future, which are inherently subject to risks and uncertainties, and if actual events turn out to be materially less favorable than the judgments we make and the assumptions we use, we may be required to record impairment charges in the future.



We had approximately $635.4 million of goodwill and indefinite-lived intangible assets recorded on our Consolidated Balance Sheet as of December 31, 2016. We assess these assets for impairment annually, or more often if required. Our assessments involve a number of estimates and assumptions that are inherently subjective, require significant judgment and regard highly uncertain matters that are subject to change. The use of different assumptions or estimates could materially affect the determination as to whether or not an impairment has occurred. In addition, if future events are less favorable than what we assumed or estimated in our impairment analysis, we may be required to record impairment charge, which could have a material impact on our consolidated financial statements.



Conflicts of interest may arise involving certain of our directors.



As of December 31, 2016, our chairman and chief executive officer, Ronald N. Tutor, and three trusts controlled by Mr. Tutor (the “Tutor Group”) owned approximately 18% of the outstanding shares of our common stock. Under the terms of Mr. Tutor’s employment agreement, he has the right to designate one nominee for election as a member of the Company’s Board of Directors so long as the Tutor Group owns at least 11.25% of the outstanding shares of the Company’s common stock. As of the date of this Form 10-K, there are 10 current directors, one of whom was appointed by Mr. Tutor in November 2013. Mr. Tutor will be able to exert significant influence over the outcome of a range of corporate matters, including significant corporate transactions requiring a shareholder vote, such as a merger or a sale of the Company or its assets. This concentration of ownership and influence in management and Board decision-making also could harm the price of our common stock by, among other things, discouraging a potential acquirer from seeking to acquire shares of our common stock or otherwise attempting to obtain control of the Company.

  

ITEM 1B. UNRESOLVED STAFF COMMENTS



None.

  

---

 

ITEM 2. PROPERTIES



We have office facilities and equipment yards in the following locations, which we believe are suitable and adequate for our current needs:













  



ITEM 3. LEGAL PROCEEDINGS



Legal Proceedings are set forth in Note 7 of the Notes to Consolidated Financial Statements and are incorporated herein by reference.

  

ITEM 4. MINE SAFETY DISCLOSURES



We do not own or operate any mines; however, we may be considered a  mine operator under the Federal Mine Safety and Health Act of 1977 because we provide construction-related services for customers in the mining industry.  Accordingly, we provide information concerning mine safety violations and other mining regulation matters in Exhibit 95 to this Form 10-K. For the year ended December 31, 2016, revenue from mine construction services was $18.8  million.

  

---

 

PART II.



ITEM 5. MARKET FOR THE REGISTRANT’S COMMON EQUITY, RELATED STOCKHOLDER MATTERS AND ISSUER PURCHASES OF EQUITY SECURITIES



Market Information



Our common stock is traded on the New York Stock Exchange under the symbol “TPC.”  The quarterly market high and low sales prices for our common stock in 2016 and 2015 were as follows:







Holders



At February 17, 2017, there were 427 holders of record of our common stock, including holders of record on behalf of an indeterminate number of beneficial owners.



Dividends and Issuer Purchases of Equity Securities



We did not pay dividends or repurchase stock during the year ended December 31, 2016;  we do not have any immediate plans to do so. Furthermore, our current debt agreements restrict us from paying dividends or repurchasing stock.



Issuance of Unregistered Securities



None.



---

 

Performance Graph



The following graph compares the cumulative 5-year total return to shareholders on our Common Stock relative to the cumulative total returns of the NYSE Composite Index and the Dow Jones Heavy Construction Index (“DJ Heavy Construction Index”). We selected the DJ Heavy Construction Index because we believe the index reflects the market conditions within the industry in which we primarily operate. The comparison of total return on investment, defined as the change in year-end stock price plus reinvested dividends, for each of the periods assumes that $100 was invested on December 31, 2011 in each of our Common Stock, the NYSE Composite Index and the DJ Heavy Construction Index, with investment weighted on the basis of market capitalization.



The comparisons in the following graph are based on historical data and are not intended to forecast the possible future performance of our Common Stock.





---

 

ITEM 6. SELECTED FINANCIAL DATA



Selected Consolidated Financial Information



The following selected financial data should be read in conjunction with Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations and Item 15. Exhibits and Financial Statement Schedules in this Annual Report. The following tables present selected financial data for the last five years. This selected financial data should be read in conjunction with the consolidated financial statements and related notes included in Item 15. Exhibits and Financial Statement Schedules.











---



The Company's results for the year ended December 31, 2014 included a positive impact related to changes in the estimated recoveries for two Civil segment projects and a Building segment hospitality and gaming project, resulting in a $0.33 increase per diluted share.



The Company's diluted EPS during the years ended December 31, 2013 and 2012 were positively impacted by $0.18 and $0.16, respectively, because of changes in the estimated recovery for the same hospitality and gaming project.



---

 





We have changed the presentation of certain items in our consolidated financial statements as of and for the year ended December 31, 2015, 2014, 2013 and 2012 for the following items: (1) Subsequent to the issuance of our 2015 consolidated financial statements we identified that certain immaterial classification adjustments, related to the offsetting of deferred assets and liabilities by tax jurisdiction, were necessary to correct the error in the classification of deferred tax assets and liabilities. See Note 6 of the Notes to Consolidated Financial Statements for additional details. (2) We early adopted ASU 2015-17, Balance Sheet Classification of Deferred Taxes (Subtopic 740-10), which requires companies to retrospectively present all deferred tax assets and deferred tax liabilities as noncurrent in a classified balance sheet. (3) During 2016, we retrospectively adopted Accounting Standards Update (“ASU”) 2015-03, Interest – Imputation of Interest (Subtopic 835-30), which requires companies to present in the balance sheet debt issuance costs related to a recognized debt liability as a direct deduction from the carrying amount of that debt liability, consistent with the presentation of debt discounts. In addition, the amortization of debt discounts is required to be presented as a component of interest expense.



The aggregate impact of the changes discussed above is as follows:

---

 

  

ITEM 7. MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS



The following discussion and analysis of our financial condition and results of operations should be read in conjunction with our Consolidated Financial Statements and the accompanying Notes to Consolidated Financial Statements included in Item 15. Exhibits and Financial Statement Schedules in this Annual Report. This discussion contains forward-looking statements, which involve risks and uncertainties. For cautions about relying on such forward-looking statements, please refer to the section entitled “Forward-Looking Statements” at the beginning of this Annual Report immediately prior to Item 1. Our actual results could differ materially from those anticipated in the forward-looking statements as a result of certain factors, including but not limited to those discussed in Item 1A. Risk Factors and elsewhere in this Annual Report.



Executive Overview



Consolidated revenue for 2016 was $5.0 billion compared to $4.9 billion for 2015. The modest improvement was attributable to higher volume in our Building segment, driven by various building projects primarily in California.



Consolidated revenue for 2015 was $4.9 billion compared to $4.5 billion for 2014. The growth was driven by increased volume in our Building and Civil segments, with various building projects in California and two large mass-transit projects in New York being the largest contributors.



Income from construction operations for 2016 was $201.9 million compared to $105.4 million for 2015. The strong increase was primarily due to significantly improved operating performance in all segments. The prior year included various unfavorable adjustments, as discussed in the next paragraph.



Income from construction operations for 2015 was $105.4 million compared to $241.7 million for 2014. The decrease was primarily due to significant project charges recorded for various Five Star Electric projects in New York in the Specialty Contractors segment, decreased activity on certain higher-margin civil projects, unfavorable adjustments related to the estimate of costs to complete an office building project in New York and the adverse Brightwater litigation-related charge for a legacy civil project.



The effective tax rate was 35.7%,  38.7% and 42.4% for 2016,  2015 and 2014, respectively. The 2016 rate was favorably impacted by rate changes associated with a shift in revenue mix between states affecting state apportionment, as well as various return-to-provision and deferred tax adjustments related to depreciation. The 2015 rate was favorably impacted by the resolution of certain state tax matters. The 2014 rate was unfavorably impacted by increased activity in higher state tax jurisdictions and higher non-deductible compensation expense.



Earnings per diluted share was $1.92,  $0.91 and $2.20 in 2016,  2015 and 2014, respectively. The strong earnings growth in 2016 was due to significantly improved operating performance in all segments, as discussed above. The primary reasons for the earnings decline in 2015 were the various above-mentioned unfavorable adjustments that impacted income from construction operations during that year.



Cash flow from operations was $113.3 million in 2016 compared to $14.1 million in 2015, and compared to a use of cash from operations of $56.7 million in 2014. The strong improvement in operating cash generation in 2016 was due to significant progress achieved on the Company’s initiative to focus on cash flow and the reduction of unbilled costs through more timely project billings and collections, and resolution and subsequent invoicing of unapproved change orders and claims. In 2016, for the first time in eight years, the Company’s cash flow from operations exceeded its net income for the year.



Consolidated new awards in 2016 were $3.7 billion compared to $4.6 billion in 2015 and $5.4 billion in 2014. The Civil and Building segments were the major contributors of new awards during 2016. The Building segment was the major contributor of new awards during 2015. New awards in 2014 were generally balanced across all three segments, with the Building segment contributing a modestly higher volume.

 

Consolidated backlog was $6.2 billion, $7.5 billion and $7.8 billion as of December 31, 2016,  2015 and 2014, respectively. The backlog at the end of 2016 was the result of revenue burn during the year that outpaced new awards in the Building and Specialty Contractors segments, and closely tracked new awards in the Civil segment. As of December 31, 2016, the mix of backlog by segment was approximately 43%,  32% and 25% for the Civil, Building and Specialty Contractors segments, respectively. The Company was awarded a $1.4 billion joint-venture mass-transit project in January 2017 that the Company will consolidate in its financial results starting in the first quarter of 2017. The backlog at the end of 2015 was primarily due to significant new awards in the Building segment, partially offset by revenue burn that outpaced new awards in the Civil and Specialty Contractors segments.



---

 

Projects in the Civil segment’s backlog typically convert to revenue over a period of three to five years, whereas projects for the Building and Specialty Contractors segments typically convert to revenue over a period of one to three years. We estimate that approximately $3.4 billion, or 54%,  of our backlog as of December 31, 2016 will be recognized as revenue in 2017.



The following table presents the changes in backlog in 2016:





---



The outlook for our Company’s growth over the next several years is the most favorable it has been in many years, particularly in the Civil segment. In addition to our large volume of backlog, we expect significant new award activity based on long-term capital spending plans by various state, local and federal customers, and typically bipartisan support for infrastructure investments. In the November 2016 U.S. election, voters in numerous states approved dozens of transportation funding measures totaling approximately $200 billion in long-term funding. The largest of these were in Los Angeles County, where Measure M, a half-cent sales tax increase, was approved and is expected to generate $120 billion of funding over the next 40 years, and in Seattle, Washington, where Sound Transit 3 was passed and is expected to generate $54 billion of funding over the next 25 years for regional transportation projects. In addition, the Trump administration envisions a significant infrastructure investment program, has identified a priority list containing dozens of “emergency and national security” projects and is preparing to present its infrastructure plan for approval and funding. Furthermore, the $305-billion Fixing America’s Surface Transportation (FAST) Act, which was approved in late 2015, is expected to provide state and local agencies with federal funding for numerous highway, bridge and mass-transit projects through 2020. Several large, long-duration civil infrastructure programs with which we are already involved are also progressing, such as California’s High-Speed Rail system and the New York Metropolitan Transportation Authority’s East Side Access project. Planning and permitting are also underway related to Amtrak’s Northeast Corridor Improvements, including the Gateway Program, which will eventually bring new rail tunnels beneath the Hudson River to connect service between New Jersey and New York’s Penn Station. Finally, sustained low interest rates and capital costs are expected to drive high demand and continued spending by private and public customers on building infrastructure projects.



For a more detailed discussion of operating performance of each business segment, corporate general and administrative expense and other items, see “Results of Segment Operations,” “Corporate, Tax and Other Matters” and “Liquidity and Financial Condition” below.

   

Results of Segment Operations



The Company provides professional services consisting of construction management, including specialty construction services involving electrical, mechanical, HVAC, plumbing and pneumatically placed concrete, to private and public customers primarily in the United States and its territories and in certain other international locations. The Company’s three principal business segments are as follows: Civil, Building and Specialty Contractors. For more information on these business segments, see “Item 1. – Business” above.



Civil Segment



Revenue and income from construction operations for the Civil segment are summarized as follows:







Revenue for 2016 decreased 12% compared to 2015, principally due to the prior-year completion of a large runway reconstruction project in New York and reduced activity in 2016 on a platform project at Hudson Yards in New York, which is nearing completion. The decrease was partially offset by increased activity on various projects, including a large tunnel project in Seattle, Washington and a large mass-transit project in California. Revenue for 2015 increased 12% compared to 2014, principally due to progress on many

---

 

projects in the New York area, including the CM006 and CS179 mass-transit projects, and increased activity on various bridge projects in the Midwest. This increase was partially offset by decreased activity on certain tunnel projects on the West Coast.



Income from construction operations increased 19% in 2016 compared to 2015, due to improved operating performance and because the prior-year results included the Brightwater litigation-related charge of $23.9 million. The increase was partially offset by the impact of the reduced volume discussed above. Income from construction operations declined 34% in 2015 compared to 2014 primarily due to reduced activity on certain higher-margin projects, the aforementioned Brightwater litigation-related charge, decreased activity on certain tunnel projects on the West Coast and net favorable adjustments in 2014 of $16.5 million due to anticipated recoveries associated with two legal rulings. The decline was partially offset by increased activity, as well as favorable adjustments in 2015 totaling $13.7 million on the runway reconstruction project in New York.



Operating margin was 10.3% in 2016, compared to 7.7% in 2015 and 13.1% in 2014. The increase in operating margin in 2016 was primarily due to the reasons discussed above that impacted revenue and income from construction operations. The margin decline in 2015 was also due to the reasons discussed above regarding changes in revenue and income from construction operations. Excluding the Brightwater litigation-related charge and favorable adjustments for the runway project in New York, operating margin in 2015 was 8.2%. Our 2014 performance benefitted from significant work performed on certain higher-margin projects.



New awards in the Civil segment totaled $1.6 billion in 2016, $1.1 billion in 2015 and $1.7 billion in 2014. New awards in 2016 included a $663 million mass-transit project in New York, approximately $277 million of new bridge projects in the Midwest, the Company’s share of $244 million of additional contract scope for a mass-transit project in California, a $107 million highway project in Virginia and a $97 million airport terminal expansion project in Guam. New awards in 2015 included a mass-transit project in New York valued at $80 million, highway projects in Delaware, Maryland and Pennsylvania valued at $70 million, $60 million and $58 million, respectively, and a tunnel extension project in New York worth $56 million. New awards in 2014 included two mass-transit projects in New York collectively valued at $844 million, a runway reconstruction project in New York valued at $243 million and three bridge projects in Wisconsin and Minnesota collectively valued at $181 million.



Backlog for the Civil segment was $2.7 billion as of December 31, 2016, consistent with $2.7 billion as of December 31, 2015 and compared to $3.6 billion as of December 31, 2014. Civil segment backlog is expected to grow in early 2017, primarily the result of a new award in January 2017 for a $1.4 billion joint-venture mass-transit project in Los Angeles that the Company will consolidate in its financial results starting in the first quarter of 2017. The segment continues to experience strong demand reflected in a large pipeline of prospective projects and substantial anticipated funding associated with various transportation measures that were voter-approved during the November 2016 election; the Trump administration’s considerable, expected infrastructure investment program; public agencies’ long-term spending plans; and the $305-billion FAST Act. The Civil segment is well-positioned to capture its share of these prospective projects. The segment, however, faces continued strong competition, including occasional aggressive bids from foreign competitors.



Building Segment



Revenue and income from construction operations for the Building segment are summarized as follows:









Revenue for 2016 increased  15% compared to 2015, principally due to increased activity on various commercial office, technology, health care, hospitality and gaming, and retail building projects in California. This increase was partially offset by the completion in 2015 of a hospitality and gaming project in Mississippi. Revenue for 2015 increased 20% compared to 2014, primarily driven by increased activity on various commercial office, technology, government, education and retail building projects in California.



Income from construction operations increased considerably in 2016 compared to 2015, when the segment experienced a slight loss. The strong increase was due to improved operating performance and prior-year unfavorable adjustments, totaling $24.3 million, to the estimated cost to complete an office building project in New York. Income from construction operations declined in 2015 compared to 2014, primarily due to the above-mentioned unfavorable adjustments and favorable adjustments in 2014 totaling $11.4 million for a large hospitality and gaming project.



Operating margin was 2.5% in 2016, compared to (0.1)% in 2015 and 1.6% in 2014. The notable margin improvement in 2016 was due to the above-mentioned factors that drove the changes in revenue and income from construction operations. The margin decline in 2015 was principally due to the factors discussed above that caused the significant decline in income from construction operations.

 

---

 

New awards in the Building segment totaled $1.3 billion in 2016, $2.4 billion in 2015 and $1.9 billion in 2014. New awards in 2016 included a hospitality and gaming project in California and another in Maryland, collectively valued at $372 million; a hospitality project in California valued at $120 million; and a multi-unit residential project in Florida valued at $72 million. New awards in 2015 included a technology research and development office project valued at $800 million and $230 million of incremental funding for a biotechnology project, both in California, and a hospitality project in Pennsylvania worth $239 million. New awards in 2014 included a multi-unit residential project in Florida worth $255 million, two hospitality and gaming projects in Mississippi and California collectively valued at $225 million and a health care project in California valued at $211 million.



Backlog for the Building segment was $2.0 billion as of December 31, 2016, compared to $2.8 billion as of December 31, 2015 and $2.2 billion as of December 31, 2014. The backlog decline in 2016 was due to strong revenue burn that outpaced new awards during the year. The Building segment continues to have a large pipeline of prospective projects, some of which have already been bid and are expected to be selected and awarded by customers during the first half of 2017. Strong demand is expected to continue due to ongoing customer spending, supported by a low interest rate environment. The Building segment is well-positioned to capture its share of prospective projects based on its strong customer relationships and long-term reputation for excellence in delivering high-quality projects on time and within budget.



Specialty Contractors Segment



Revenue and income from construction operations for the Specialty Contractors segment are summarized as follows:









Revenue for 2016 increased slightly compared to 2015. Increased activity on two electrical projects in the western United States and electrical projects in New York was mostly offset by decreased activity on various mechanical projects in New York. Revenue for 2015 decreased 6% compared to 2014, primarily due to decreased activity on various smaller electrical projects in the southern United States that were impacted in 2015 by the low price of oil, electrical projects at the World Trade Center and mechanical projects at the United Nations in New York. This decrease was partially offset by increased activity on various electrical projects at Hudson Yards, two large mass-transit projects and various other electrical, mechanical and concrete placement projects, all in New York.



Income from construction operations increased 141% in 2016 compared to 2015 because 2015 included unfavorable adjustments totaling $45.6 million for various Five Star Electric projects in New York, none of which were individually material. Income from construction operations declined 69% in 2015 compared to 2014, primarily due to the aforementioned unfavorable adjustments related to Five Star Electric.



Operating margin was 3.1% in 2016,  compared to 1.3% in 2015 and 3.9% in 2014. The margin improvement in 2016 was due to the factors mentioned above that impacted income from construction operations. In addition, throughout 2016, management focused on improving operational performance at its Five Star Electric and WDF business units in New York and, as a result, considered it a transitional year for the Specialty Contractors segment. The operational improvement is reflected in the segment’s increased income from construction operations and operating margin. Further operating margin improvement is anticipated for the segment in 2017. The margin decline in 2015 was principally due to the aforementioned unfavorable adjustments at Five Star Electric.



New awards in the Specialty Contractors segment totaled $867 million in 2016, $1.1 billion in 2015 and $1.7 billion in 2014. New awards in 2016 included various mechanical projects in New York collectively valued at approximately $146 million, several electrical projects in the southern United States totaling approximately $93 million and an electrical subcontract for a mass-transit project in New York valued at $86 million. New awards in 2015 included an electrical subcontract valued at $90 million for a mass-transit project in New York and an electrical subcontract valued at $73 million for a Hudson Yards office tower in New York. New awards in 2014 included a $321 million electrical subcontract for a mass-transit project in New York and two contracts totaling $175 million for electrical work on other mass-transit projects in New York and California.



Backlog for the Specialty Contractors segment was $1.6 billion as of December 31, 2016, compared to $1.9 billion as of December 31, 2015 and $2.1 billion as of December 31, 2014. The Specialty Contractors segment has a significant pipeline of prospective projects, with demand for its services supported by strong continued spending on civil and building projects. The Specialty Contractors segment is well-positioned to capture its share of prospective projects based on the size and scale of our business units that operate in New York, Texas, Florida and California and the strong reputation held by these business units for high-quality work on larger, complex projects.



---

 

Corporate, Tax and Other Matters



Corporate General and Administrative Expense



Corporate general and administrative expenses were $60.2 million in 2016, $54.2 million in 2015 and $54.6 million in 2014. The higher corporate general and administrative expenses in 2016 were predominantly due to increased compensation expense attributable to improved financial results and the hiring of several key executives. In 2015, there was lower performance-based compensation expense compared to 2014.



Other Income (Expense), Interest Expense and Provision for Income Taxes







Other income, net, decreased by $6.6 million in 2016 compared to 2015, and improved $21.8 million in 2015 compared to 2014. Other income in 2015 included adjustments to decrease contingent earn-out liabilities related to prior business acquisitions. Other expense in 2014 included earn-out expense related to past business acquisitions.



Interest expense increased $14.7 million for the year ended December 31, 2016 compared to the prior year. Interest expense for the year ended December 31, 2015 was comparable to 2014. The increase for the year ended December 31, 2016 was primarily due to cash and non-cash interest expense related to the Convertible Notes issued in June 2016, as well as an increase in non-cash interest expense associated with fees related to two amendments to the Company’s 2014 Credit Facility. The year ended December 31, 2016 was also impacted by higher net borrowing rates, which were 78 basis points higher compared to the same period in 2015, partially offset by a $21.4 million reduction in the Company’s average year-over-year borrowings. 



The effective income tax rate was 35.7% for 2016, 38.7% for 2015 and 42.4% for 2014.  The effective tax rate for 2016 compared to 2015 was favorably impacted by rate changes associated with a shift in revenue mix between states affecting state apportionment, as well as various return-to-provision and depreciation adjustments. The largest contributor to the decreased tax rate in 2015 compared to 2014 was the resolution of certain state tax matters.

  

Liquidity and Financial Condition



Liquidity is provided by available cash and cash equivalents, cash generated from operations, credit facilities and access to capital markets. We have a committed line of credit totaling $300 million, which may be used for revolving loans, letters of credit and/or general purposes. We believe that for at least the next 12 months, cash generated from operations, along with our unused credit capacity of $147.3 million and cash position, is sufficient to support operating requirements. Additionally, over the long-term we may from time to time use excess cash to repurchase our debt.



Cash and Working Capital



Cash and cash equivalents were $146.1 million as of December 31, 2016 compared to $75.5 million as of December 31, 2015. These were comprised of cash held by us and available for general corporate purposes of $49.5 million and $18.5 million, respectively, and our proportionate share of cash held by joint ventures, available only for joint-venture-related uses including distributions to joint‑venture partners of $96.6 million and $57.0 million, respectively. In addition, our restricted cash, held primarily to secure insurance-related contingent obligations, was $50.5 million as of December 31, 2016, compared to $45.9 million as of December 31, 2015.



During the year ended December 31, 2016, net cash provided by operating activities was $113.3 million ($108.8 million of which was generated in the third and fourth quarters), due primarily to favorable operating results, somewhat offset by changes in net investment in working capital. The change in working capital primarily reflects increases in accounts receivable (both trade accounts receivable and retention) related to billing activity, offset by a reduction of costs and estimated earnings in excess of billings, which management is continuing to resolve and collect. In 2016, for the first time in eight years, the Company’s cash flow from operations exceeded its net income for the year. During the year ended December 31, 2015, $14.1 million in cash was provided from operating activities, primarily due to cash generated from earnings sources being mostly offset by increased net investment in working capital.



The $99.3 million improvement in cash flow from operations for the year ended December 31, 2016 compared to the year ended December 31, 2015 is reflective of improved year-over-year profitability and lower net investment in working capital resulting from a significant reduction in costs and estimated earnings in excess of billings. The improvement in cash generation in 2016 compared to

---

 

2015 is even more pronounced when considering there were significant collections by the Company in the first quarter of 2015 related to the settlements of past disputes over the CityCenter project in Las Vegas, Nevada and a hospital project in Santa Monica, California.



During 2016, we used $18.5 million of cash from investing activities, due primarily to the acquisition of property and equipment, compared to the use of cash of $32.4 million for investing activities during 2015, which was primarily related to the acquisition of property and equipment of $35.9 million, offset by $5.0 million in proceeds from the sale of property and equipment.



During 2016, we utilized $24.2 million of cash from financing activities, primarily due to the net paydown of debt and the payment of $15.1 million in debt issuance costs associated with two amendments to the 2014 Credit Facility and the issuance of $200.0 million of Convertible Notes. The net proceeds from the Convertible Notes were used to prepay $125.0 million of the borrowings outstanding under our Term Loan, pay down $69.0 million of borrowings outstanding under our 2014 Revolver and pay $6.0 million of fees related to the offering. Net cash used in financing activities for 2015 was $41.8 million, which was primarily due to the pay down of debt under the 2014 Credit Facility. 



As of December 31, 2016, we had working capital of $1.3 billion, a ratio of current assets to current liabilities of 1.87 and a ratio of debt to equity of 0.49 compared to working capital of $1.2 billion, a ratio of current assets to current liabilities of 1.80 and a ratio of debt to equity of 0.58 at December 31, 2015.



Debt



2014 Credit Facility



Under our 2014 Revolver, we had outstanding borrowings of $152.5 million as of December 31, 2016 and $158.0 million as of December 31, 2015. The 2014 Revolver balances reported on the Consolidated Balance Sheets as of December 31, 2016 and 2015 include unamortized debt issuance cost of $4.5 million and $2.2 million, respectively. We utilized the 2014 Revolver for letters of credit in the amount of $0.2 million as of December 31, 2016 and 2015, respectively.



On June 5, 2014, the Company entered into a Sixth Amended and Restated Credit Agreement (the “Original Facility,” with subsequent amendments discussed herein, the “2014 Credit Facility”), with Bank of America, N.A. as Administrative Agent, Swing Line Lender and L/C Issuer and a syndicate of other lenders. The 2014 Credit Facility provides for a $300 million revolving credit facility (the “2014 Revolver”), a $250 million term loan (the “Term Loan”) and a sublimit for the issuance of letters of credit up to the aggregate amount of $150 million, all maturing on May 1, 2018. Borrowings under both the 2014 Revolver and the Term Loan bear interest based either on Bank of America’s prime lending rate or the London Interbank Offered Rate (“LIBOR”), each plus an applicable margin ranging from 1.25% to 3.00% contingent upon the latest Consolidated Leverage Ratio.



During the first half of 2016, the Company entered into two amendments to the Original Facility (the “Amendments”): Waiver and Amendment No. 1, entered into on February 26, 2016 (“Amendment No. 1”), and Consent and Amendment No. 2, entered into on June 8, 2016 (“Amendment No. 2”). In Amendment No. 1, the lenders waived the Company’s violation of its consolidated leverage ratio covenant and consolidated fixed charge coverage ratio covenant. These violations were the result of the Company’s financial results for the year ended December 31, 2015, which included the previously reported $23.9 million non-cash, pre-tax charge related to an adverse ruling on the Brightwater litigation matter in the third quarter of 2015, as well as $45.6 million of pre-tax charges in the third and fourth quarters of 2015 for various Five Star Electric projects. In Amendment No. 2, the lenders consented to the issuance of the Convertible Notes subject to certain conditions, including the prepayment of $125 million on the Term Loan and the paydown of $69 million on the 2014 Revolver, and consented to a potential sale transaction of one of the Company’s business units in its Building segment, which the Company later decided not to sell.



In addition to the Amendments’ provisions discussed above, the Amendments also modified other provisions and added new provisions to the Original Facility, and Amendment No. 2 superseded and modified some of the provisions of Amendment No. 1. The following reflects the more significant changes to the Original Facility and the results of the Amendments that are now reflected in the 2014 Credit Facility. Unless otherwise noted, the changes below were primarily the result of Amendment No. 1: (1) The Company may utilize LIBOR-based borrowings. (Amendment No. 1 precluded the use of LIBOR-based borrowings until the Company filed its compliance certificate for the fourth quarter of 2016; however, Amendment No. 2 negated this preclusion.) (2) The Company is subject to an increased rate on borrowings, with such rate being 100 basis points higher than the highest rate under the Original Facility if the Company’s consolidated leverage ratio is greater than 3.50:1.00 but not more than 4.00:1.00, and an additional 100 basis points higher if the Company’s consolidated leverage ratio is greater than 4.00:1.00. (3) The Company will be subject to increased commitment fees if the Company’s consolidated leverage ratio is greater than 3.50:1.00. (4) The impact of the Brightwater litigation matter in the third quarter of 2015 is to be excluded from the calculation of the Company’s consolidated leverage ratio and consolidated fixed charge coverage ratio covenants. (5) Interest payments are due on a monthly basis; however, if the Company is in compliance with its consolidated leverage ratio and consolidated fixed charge coverage ratio covenants provided in the Original Facility as of December 31, 2016, the timing of interest payments will revert to the terms of the Original Facility. As of December 31,

---

 

2016, the Company is in compliance with its consolidated leverage ratio and consolidated fixed charge coverage ratio covenants provided in the Original Facility and the timing of our interest payments reverted back to the terms of the Original Facility, quarterly for the Term Loan and base rate borrowings and upon maturity for Eurodollar borrowings. (6) The accordion feature of the Original Facility, which would have allowed either an increase of $300 million in the 2014 Revolver or the establishment of one or more new term loan commitments, is no longer available. (7) The Company’s maximum allowable consolidated leverage ratio was increased to 4.25:1.00 for the first, second and third quarters of 2016 after which it returns to the Original Facility’s range of 3.25:1.00 to 3.00:1.00. (Amendment No. 1 increased the Company’s maximum allowable consolidated leverage ratio covenant requirements to 4.25:1.00 for the first quarter of 2016 and 4.0:1.0 for the second and third quarters of 2016. Amendment No. 2 increased the maximum allowable consolidated leverage ratio covenant requirements to 4.25:1.00 for the second and third quarters of 2016.) (8) The Company is subject to additional covenants regarding its liquidity, including a cap on the cash balance in the Company’s bank account and a weekly minimum liquidity requirement (based on specified available cash balances and availability under the 2014 Revolver). (9) The Company is required to achieve certain cumulative quarterly cash collection milestones, which were eased somewhat in Amendment No. 2. (10) The Company is required to make additional quarterly principal payments, which will be applied to the Term Loan balloon payment, with some of the payments based on a percentage of certain forecasted cash collections for the prior quarter. This change was effective in the fourth quarter of 2016. (11) The lenders’ collateral package was increased by pledging to the lenders (i) the equity interests of each direct domestic subsidiary of the Company and (ii) 65% of the stock of each material first-tier foreign restricted subsidiary of the Company. (12) The 2014 Credit Facility will now mature on May 1, 2018, as opposed to June 5, 2019, the maturity date of the Original Facility.



The table below presents our actual and required consolidated fixed charge coverage ratio and consolidated leverage ratio under the 2014 Credit Facility for the period, which are calculated on a four-quarter rolling basis:







As of the filing date of this Form 10-K we are in compliance and expect to continue to be in compliance with the financial covenants under the 2014 Credit Facility.



2010 Senior Notes



In October 2010, the Company issued $300 million of 7.625% Senior Notes due November 1, 2018, (the “2010 Notes”) in a private placement offering. Interest on the 2010 Notes is payable semi-annually on May 1 and November 1 of each year. The Company may redeem the 2010 Notes at par beginning on November 1, 2016, which was not exercised as of December 31, 2016. At the date of any redemption, any accrued and unpaid interest would also be due.



Convertible Notes



On June 15, 2016, we completed an offering of $200 million of 2.875% Convertible Senior Notes due June 15, 2021 (the “Convertible Notes”). The Convertible Notes are senior unsecured obligations of the Company. Interest on the Convertible Notes is payable on June 15 and December 15 of each year, commencing on December 15, 2016, until the maturity date. We used the proceeds to prepay $125.0 million of our Term Loan, pay down $69.0 million of our 2014 Revolver, and pay $6.0 million of fees related to the offering. For additional information regarding the terms of our Convertible Notes, refer to Note 5 of the Notes to Consolidated Financial Statements. As of December 31, 2016, none of the conversion provisions of our Convertible Notes have been triggered.



Equipment financing and mortgages



The Company has certain loans entered into for the purchase of specific property, plant and equipment and secured by the assets purchased. The aggregate balance of equipment financing loans was approximately $84.9 million and $115.6 million at December 31, 2016 and 2015, respectively, with interest rates ranging from 1.90% to 5.93% with equal monthly installment payments over periods up to ten years with additional balloon payments of $12.4 million in 2021 and $6.3 million in 2022 on the remaining loans outstanding at December 31, 2016. The aggregate balance of mortgage loans was approximately $16.7 million and $17.7 million at December 31, 2016 and 2015, respectively, with interest rates ranging from a fixed 2.50% to LIBOR plus 3% and equal monthly installment payments over periods up to seven years with additional balloon payments of $2.6 million in 2018, $2.9 million in 2021 and $6.7 million in 2023.



---

 

Off-Balance Sheet Arrangements



None



Contractual Obligations



Our outstanding contractual obligations as of December 31, 2016 are summarized in the following table:







---



---

 

Critical Accounting Policies



Our discussion and analysis of our financial condition and results of operations is based upon our Consolidated Financial Statements, which have been prepared in accordance with GAAP. Our significant accounting policies are described in Note 1 of the Notes to Consolidated Financial Statements. The preparation of the Consolidated Financial Statements requires us to make estimates and judgments that affect the reported amounts of assets, liabilities, revenue and expenses, and related disclosure of contingent assets and liabilities. Estimates are based on information available through the date of the issuance of the financial statements; accordingly, actual results in future periods could differ from these estimates. Significant judgments and estimates used in the preparation of the Consolidated Financial Statements apply to the following critical accounting policies:



Method of Accounting for Contracts — Contract revenue is recognized on the percentage-of-completion method based on contract cost incurred to date compared to total estimated contract cost. The estimates used in the percentage-of-completion method during the contract performance period require judgment and assumptions regarding both future events and the evaluation of contingencies such as the impact of change orders, liability claims, other contract disputes, the achievement of contractual performance standards, and potential variances in project schedule and costs. Changes to the total estimated contract cost, either due to unexpected events or revisions to management’s initial estimates, for a given project are recognized in the period in which they are determined.



In certain instances, we provide guaranteed completion dates and/or achievement of other performance criteria. Failure to meet schedule or performance guarantees could result in unrealized incentive fees and/or liquidated damages. In addition, depending on the type of contract, unexpected increases in contract cost may be unrecoverable, resulting in total cost exceeding revenue realized from the projects. The Company generally provides limited warranties for work performed, with warranty periods typically extending for a limited duration following substantial completion of the Company’s work on a project. Historically, warranty claims have not resulted in material costs incurred.



Claims arising from construction contracts have been made against the Company by customers, and the Company has made claims against customers for cost incurred in excess of current contract provisions. The Company recognizes revenue, but not profit, for certain significant claims when it is determined that recovery of incurred cost is probable and the amounts can be reliably estimated. These requirements are satisfied under GAAP’s Accounting Standards Codification (“ASC”) 605-35-25 when the contract or other evidence provides a legal basis for the claim, additional costs were caused by circumstances that were unforeseen at the contract date and not the result of deficiencies in the Company’s performance, claim-related costs are identifiable and considered reasonable in view of the work performed, and evidence supporting the claim is objective and verifiable. 



Recoverability of Goodwill — Goodwill represents the excess of amounts paid over the fair value of net assets acquired from an acquisition. In order to determine the amount of goodwill resulting from an acquisition, we perform an assessment to determine the value of the acquired company's tangible and identifiable intangible assets and liabilities. In our assessment, we determine whether identifiable intangible assets exist, which typically include backlog, customer relationships and trade name.



We test goodwill for impairment annually for each reporting unit in the fourth quarter of the fiscal year, and between annual tests if events occur or circumstances change which suggest that goodwill should be evaluated. Such events or circumstances include significant changes in legal factors and business climate, recent losses at a reporting unit, and industry trends, among other factors. A reporting unit is defined as an operating segment or one level below an operating segment. Our impairment tests are performed at the operating segment level as they represent our reporting units.



The impairment test is a two-step process. During the first step, we estimate the fair value of the reporting unit using income and market approaches, and compare that amount to the carrying value of that reporting unit. In the event the fair value of the reporting unit is determined to be less than the carrying value, a second step is required. The second step requires us to perform a hypothetical purchase allocation for that reporting unit and to compare the resulting current implied fair value of the goodwill to the current carrying value of the goodwill for that reporting unit. In the event that the current implied fair value of the goodwill is less than the carrying value, an impairment charge is recognized.



During the fourth quarter, we conducted our annual goodwill impairment test. The impairment evaluation process includes, among other things, making assumptions about variables such as revenue growth rates, profitability, discount rates, and industry market multiples, which are subject to a high degree of judgment.



Material assumptions used in the impairment analysis included the weighted average cost of capital (WACC). As of October 1, 2016, changes of 0.5% in the WACC rate would have resulted in changes in the fair value of reporting units ranging from $(30) million to $35 million, which would not have changed the conclusions reached in our annual goodwill impairment test.



New Accounting Pronouncements — For discussion of recently adopted accounting standards and updates, see Note 1 of the Notes to Consolidated Financial Statements.

  

---

 

ITEM 7A. QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK



Interest rate risk is our primary market risk exposure. Borrowing under our Credit Agreement and certain other debt obligations have variable interest rates and are therefore subject to interest rate risk. As of December 31, 2016, we had approximately $211.3 million of net borrowings with variable interest rates. If short-term floating interest rates were to increase by 0.50%, interest on these borrowings would increase by approximately $1.1 million.

  

ITEM 8. FINANCIAL STATEMENTS AND SUPPLEMENTARY DATA



The Report of Independent Registered Public Accounting Firm, Consolidated Financial Statements and Supplementary Schedules are set forth in Item 15 in this Annual Report on Form 10-K and are incorporated herein by reference.

  

ITEM 9. CHANGES IN AND DISAGREEMENTS WITH ACCOUNTANTS ON ACCOUNTING AND FINANCIAL DISCLOSURE



None.

  

ITEM 9A. CONTROLS AND PROCEDURES



Evaluation of Disclosure Controls and Procedures — An evaluation, of the effectiveness of the design and operation of our disclosure controls and procedures as defined by Rule 13a-15(e) under the Securities Exchange Act of 1934, as amended (“Exchange Act”), as of December 31, 2016 was made under the supervision and with the participation of our management, including our Chief Executive Officer and Chief Financial Officer. Based upon that evaluation, the Chief Executive Officer and Chief Financial Officer concluded that, as of December 31, 2016, our disclosure controls and procedures were effective, in that they provide reasonable assurance that information required to be disclosed in our reports filed or submitted under the Exchange Act were recorded, processed, summarized and reported within the time periods specified in the SEC’s rules and forms. Our disclosure controls and procedures are designed to ensure that information we are required to disclose in such reports is accumulated and communicated to management, including our Chief Executive Officer and Chief Financial Officer, as appropriate, to allow timely decisions regarding required disclosures.



Management’s Report on Internal Control over Financial Reporting — Our management, under the supervision of our Chief Executive Officer and Chief Financial Officer, is responsible for establishing and maintaining an adequate system of internal control over financial reporting as such term is defined in Exchange Act Rules 13a—15(f). In designing and evaluating our system of internal control over financial reporting, we recognize that inherent limitations exist in any control system no matter how well designed and operated, and we can only provide reasonable, not absolute, assurance of achieving the desired control objectives. In making this assessment, management utilized the criteria issued in Internal Control — Integrated Framework (2013) issued by the Committee of Sponsoring Organizations of the Treadway Commission.  Based on this assessment, management concluded that, as of December 31, 2016, our internal control over financial reporting was effective based on those criteria.



Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements. In addition, projections of any evaluation of the effectiveness to future periods are subject to the risk that controls may become inadequate due to changes in conditions, or that the degree of compliance with policies and procedures may deteriorate.



Deloitte & Touche LLP, the independent registered public accounting firm that audited our consolidated financial statements included in this Annual Report on Form 10-K, has issued an attestation report on the Company’s internal control over financial reporting as of December 31, 2016. This report appears on page 31 of this Form 10-K.



Changes in Internal Control over Financial Reporting — There were no changes in our internal control over financial reporting for the quarter ended December 31, 2016 that have materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.

---

 

REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM



To the Board of Directors and Stockholders of

Tutor Perini Corporation

Sylmar, California



We have audited the internal control over financial reporting of Tutor Perini Corporation and subsidiaries (the "Company") as of December 31, 2016, based on criteria established in Internal Control — Integrated Framework (2013) issued by the Committee of Sponsoring Organizations of the Treadway Commission. The Company's management is responsible for maintaining effective internal control over financial reporting and for its assessment of the effectiveness of internal control over financial reporting, included in the accompanying Management’s Report on Internal Control Over Financial Reporting. Our responsibility is to express an opinion on the Company's internal control over financial reporting based on our audit.



We conducted our audit in accordance with the standards of the Public Company Accounting Oversight Board (United States). Those standards require that we plan and perform the audit to obtain reasonable assurance about whether effective internal control over financial reporting was maintained in all material respects. Our audit included obtaining an understanding of internal control over financial reporting, assessing the risk that a material weakness exists, testing and evaluating the design and operating effectiveness of internal control based on the assessed risk, and performing such other procedures as we considered necessary in the circumstances. We believe that our audit provides a reasonable basis for our opinion.



A company's internal control over financial reporting is a process designed by, or under the supervision of, the company's principal executive and principal financial officers, or persons performing similar functions, and effected by the company's board of directors, management, and other personnel to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles. A company's internal control over financial reporting includes those policies and procedures that (1) pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of the assets of the company; (2) provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles, and that receipts and expenditures of the company are being made only in accordance with authorizations of management and directors of the company; and (3) provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use, or disposition of the company's assets that could have a material effect on the financial statements.



Because of the inherent limitations of internal control over financial reporting, including the possibility of collusion or improper management override of controls, material misstatements due to error or fraud may not be prevented or detected on a timely basis. Also, projections of any evaluation of the effectiveness of the internal control over financial reporting to future periods are subject to the risk that the controls may become inadequate because of changes in conditions, or that the degree of compliance with the policies or procedures may deteriorate.



In our opinion, the Company maintained, in all material respects, effective internal control over financial reporting as of December 31, 2016, based on the criteria established in Internal Control — Integrated Framework (2013) issued by the Committee of Sponsoring Organizations of the Treadway Commission.



We have also audited, in accordance with the standards of the Public Company Accounting Oversight Board (United States), the consolidated financial statements as of and for the year ended December 31, 2016 of the Company and our report dated February 23, 2017 expressed an unqualified opinion on those financial statements.



/s/ Deloitte & Touche LLP



Los Angeles, California



February 23, 2017





---

 

 



ITEM 9B. OTHER INFORMATION



None.  

PART III.



ITEM 10. DIRECTORS, EXECUTIVE OFFICERS AND CORPORATE GOVERNANCE



The information required by this Item 10 is hereby incorporated by reference from our definitive proxy statement to be filed within 120 days after the end of 2016.

  

ITEM 11. EXECUTIVE COMPENSATION



The information required by this Item 11 is hereby incorporated by reference from our definitive proxy statement to be filed within 120 days after the end of 2016.

  

ITEM 12. SECURITY OWNERSHIP OF CERTAIN BENEFICIAL OWNERS AND MANAGEMENT AND RELATED STOCKHOLDER MATTERS



The information required by this Item 12 is hereby incorporated by reference from our definitive proxy statement to be filed within 120 days after the end of 2016.

  

ITEM 13. CERTAIN RELATIONSHIPS AND RELATED TRANSACTIONS, AND DIRECTOR INDEPENDENCE



The information required by this Item 13 is hereby incorporated by reference from our definitive proxy statement to be filed within 120 days after the end of 2016.

  

ITEM 14. PRINCIPAL ACCOUNTANT FEES AND SERVICES



The information required by this Item 14 is hereby incorporated by reference from our definitive proxy statement to be filed within 120 days after the end of 2016.  

  

---

 

PART IV.



ITEM 15. EXHIBITS AND FINANCIAL STATEMENT SCHEDULES



TUTOR PERINI CORPORATION AND SUBSIDIARIES



1.            Financial Statements:

Our consolidated financial statements as of December 31, 2016 and 2015 and for each of the three years in the period ended December 31, 2016 and the notes thereto, together with the report of the independent registered public accounting firm on those consolidated financial statements are hereby filed as part of this Annual Report on Form 10-K, beginning on page F-1.



2.           Financial Statement Schedules:

All consolidated financial statement schedules are omitted because of the absence of the conditions under which they are required or because the required information is included in the Consolidated Financial Statements and in the Notes thereto.



3.           Exhibits:



EXHIBIT INDEX



The following designated exhibits are, as indicated below, either filed herewith or have heretofore been filed with the SEC under the Securities Act of 1933 or the Securities Act of 1934 and are referred to and incorporated herein by reference to such filings.



---

*Management contract or compensatory arrangement required to be filed as an exhibit pursuant to Item 15(a)(3) of Form 10-K

---

 

SIGNATURES



Pursuant to the requirements of Section 13 or 15(d) of the Securities Exchange Act of 1934, the Company has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.





Pursuant to the requirements of the Securities Exchange Act of 1934, this report has been signed below by the following persons on behalf of the Company and in the capacities and on the dates indicated.